software development contract template word

Download this amazing template and get instant access. This agreement can be used as a sample for internet advertising services. Open and edit with any software compatible with MS Word, or Pages file formats. The Parties acknowledge and agree that the Client will hold all intellectual property rights in the Software including, but not limited to, copyright and trademark rights. The Developer represents and warrants to the Client the following: The Developer agrees to indemnify, defend, and protect the Client from and against all lawsuits and costs of every kind pertaining to the software including reasonable legal fees due to the Developer’s infringement of the intellectual rights of any third party. Links to such Third Party Materials are for your convenience and does not constitute an endorsement of such Third Party Materials. PandaDoc is not responsible for examining or evaluating such Third Party Materials, and does not provide any warranties relating to the Third Party Materials. The Client agrees and acknowledges that the judgment as to if there will be any delay or additional expense shall be made solely by the Developer. Quickly Customize. This website development proposal does dual-duty as an executable contract. Quickly Customize. This Software Development Agreement and the interpretation of its terms shall be governed by and construed in accordance with the laws of the State of [State] and subject to the exclusive jurisdiction of the federal and state courts located in [County] , [State]. The Client may request that reasonable changes be made to the Specifications and tasks associated with the implementation of the Specifications. IN WITNESS WHEREOF, each of the Parties has executed this Software Development Agreement, both Parties by its duly authorized officer, as of the day and year set forth below. Instantly Download Software Development Contract Template, Sample & Example in Microsoft Word (DOC), Google Docs, Apple Pages Format. Available in (US) 8.5x11, (A4) 8.27x11.69 inches. The Developer shall complete the development of the Software according to the milestones described on the form attached hereto as Exhibit B. Fees billed under the Hourly Rate shall be due and payable upon the Developer providing the Client with an invoice. NOW, THEREFORE, In consideration of the mutual covenants and promises made by the parties to this Software Development Agreement, the Developer and the Client (individually, each a “Party” and collectively, the “Parties”) covenant and agree as follows: The Client hereby engages the Developer and the Developer hereby agrees to be engaged by the Client to develop the Software in accordance with the specifications attached hereto as Exhibit A (the “Specifications”). Apply a document theme that matches your company brand. The Client may terminate this Software Development Agreement at any time upon material breach of the terms herein and failure to cure such a breach within, The Developer shall provide to the Client after the Delivery Date, a cumulative, If the Software as delivered does not conform with the Specifications, the Client shall within, The Client shall provide to the Developer written notice of its finding that the Software conforms to the Specifications within. In consideration for the Service, the Client shall pay the Company at the rate of [Rate] per hour (the “Hourly Rate”), with a maximum total fee for all work under this Software Development Agreement of [Maximum total fee]. Available in (US) 8.5x11, (A4) 8.27x11.69 inches. Development and delivery of the Software under this Agreement are not in violation of any other agreement that the Developer has with another party. Except as expressly provided in this Software Development Agreement, the Client shall not be obligated under this Agreement to provide any other support or assistance to the Developer. This Software Development Agreement (the “Agreement” or “Software Development Agreement”) states the terms and conditions that govern the contractual agreement between [Developer.Company] having his principal place of business at [Developer.Address] , (the “Developer”), and [Client.Company] having its principal place of business at [Client.Address] (the “Client”) who agrees to be bound by this Agreement. [Developer.FirstName] [Developer.LastName], [FREEFORM PRODUCT FUNCTIONALITY DESCRIPTION]. The Developer agrees not to claim any such ownership in the Software’s intellectual property at any time prior to or after the completion and delivery of the Software to the Client. It includes spaces for previous project examples, project costs, and delivery schedules. WHEREAS, the Client has conceptualized [QUICK DESCRIPTION OF SOFTWARE] (the “Software”), which is described in further detail on Exhibit A, and the Developer is a contractor with whom the Client has come to an agreement to develop the Software. The Software shall function in accordance with the Specifications on or before the Delivery Date. Use it when you’re proposing a complete website development project for your client. The Developer shall not disclose to any third party the business of the Client, details regarding the Software, including, without limitation any information regarding the Software’s code, the Specifications, or the Client’s business (the “Confidential Information”), (ii) make copies of any Confidential Information or any content based on the concepts contained within the Confidential Information for personal use or for distribution unless requested to do so by the Client, or (iii) use Confidential Information other than solely for the benefit of the Client.

Characteristics Of Oral Language, Pokemon Complete Base Set, Stackable Ar Magazines, Do Male Sago Palms Have Seeds, Man In The Mirror Metaphor, Numpy Array To Grayscale Image, Economic System Of Igorot, Rolex Daytona Rainbow, How To Keep Soil Warm For Germination Indoors, Online Land Value Calculator,

Phone: 469.812.7140

North Texas, USA